Welcome to Wyne Builders. These Terms and Conditions govern your use of our services and website. By accessing or using our services, you agree to comply with these terms. If you do not agree with any part of these terms, please refrain from using our services.

1. Definitions

• Company: Wyne Builders, referred to as “we,” “us,” or “our.”
• Client: The person or entity using our services, referred to as “you” or “your.”
• Services: Includes all construction, renovation, sale/purchase, construction material supply and other related services provided by Wyne Builders.
• Agreement: The contract between Wyne Builders and the Client, including these terms and conditions.

2. Scope of Services

• We provide construction, renovation, and related services as agreed upon in a formal contract.
• All services will be performed by industry standards and regulatory requirements.
• Any modifications to the scope of work must be agreed upon in writing by both parties.

3. Quotations & Payments

• Quotations are valid for a specified period as mentioned in the quotation document.
• A deposit may be required before commencing work, with payment milestones outlined in the contract.
• Full payment must be made upon completion of work, unless otherwise agreed.
• Late payments may be subject to interest charges.

4. Client Responsibilities

• You agree to provide accurate information regarding project requirements.
• You must ensure access to the site and necessary utilities for work to be carried out.
• Any delays caused by the Client (e.g., lack of access, failure to obtain necessary permissions) may lead to additional costs and revised project timelines.

5. Changes & Cancellations

• Requests for changes must be made in writing and may result in additional costs.
• If the Client cancels the project after work has commenced, the Client will be responsible for any costs incurred up to the point of cancellation.

6. Warranties & Liability

• We provide a warranty on workmanship for a specified period, as stated in the contract.
• Any damage caused by misuse, neglect, or third-party contractors is not covered under warranty.
• We are not liable for delays due to unforeseen circumstances such as adverse weather, supplier shortages, or government regulations.

7. Health & Safety

• We adhere to all applicable health and safety regulations.
• The Client must inform us of any site hazards before work begins.
• We reserve the right to halt work if conditions are deemed unsafe.

8. Intellectual Property

• Any designs, plans, or materials created by Wyne Builders remain our property unless otherwise agreed.
• Unauthorized reproduction or distribution of our intellectual property is prohibited.

9. Dispute Resolution

• Any disputes shall first be attempted to be resolved through mutual discussions.
• If unresolved, disputes may be subject to mediation or legal proceedings as per local jurisdiction.

10. Governing Law

• These terms are governed by the laws of [Insert Jurisdiction].
• Any legal disputes will be handled in the courts of [Insert Jurisdiction.

11. Amendments

• We reserve the right to update these terms at any time.
• Continued use of our services after changes constitute acceptance of the revised terms.

For any questions regarding these Terms and Conditions, please contact us at [Insert Contact Information].

By using Wyne Builders’ services, you acknowledge that you have read, understood, and agreed to these Terms and Conditions.